Laserfiche WebLink
; , <br /> Insurance coverage specified in this Agreement constitutes the minimum requirements and said <br /> requirements shall not lessen or limit the liability of the Consulting Engineer under the terms of the <br /> Agreement. The Consulting Engineer shall procure and maintain at his own cost and expense, any <br /> additional kinds and amounts of insurance that, in the Consulting Engineer's own judgment, may be <br /> necessary for the Consulting Engineer's proper protection in the prosecution of the work.Neither <br /> Party shall be liable to the other Party for incidental, indirect, special or consequential damages. <br /> K. COPYRIGHT ASSIGNMENT. The Consulting Engineer assigns to the City any and all of , <br /> Consulting Engineer's rights under copyright laws for work prepared by the Consulting Engineer, its , <br /> employees, subcontractors or agents in connection with this Contract, including any and all rights to � <br /> register said copyright,renewal rights, determination rights and import rights. The Consulting <br /> Engineer agrees to execute any additional documents the City may request to effectuate the <br /> assignment of said copyright. <br /> L. NO BID RIGGING, BID ROTATION. The Consulting Engineer certifies, in accordance with <br /> Section 33E-11 of the Illinois Criminal Code,that the Consulting Engineer is not barred from bidding <br /> on contracts as a result of a violation of either Section 33E-3, Bid Rigging, or Section 33E-4, Bid <br /> Rotating, of the Illinois Criminal Code. The Consulting Engineer so certifies in the Non-Collusion <br /> Statement, attached and marked herein as Exhibit G and incorporated herein by reference. <br /> M. _NO DELINQUENT TAXES. The Consulting Engineer agrees that it is not delinquent in payment <br /> of any and all debt in any State or any political subdivisions therein and shall so certify in the <br /> Affidavit of No Delinquent Taxes, attached and marked herein as Exhibit G, and incorporated herein <br /> by reference. <br /> N. DRUG FREE WORKPLACE. The Consulting Engineer agrees that it shall comply with the <br /> Illinois Drug Free Workplace Act, 30 ILCS 580/1, et seq. If the Consulting Engineer has twenty-five <br /> (25)or more employees or this contract is for more than Five Thousand Dollars($5,000.00), the <br /> Consulting Engineer shall provide to the City the Drug Free Workplace Certification attached and <br /> marked herein as E�ibit G and incorporated herein by reference. <br /> O. SEVERABILITY. If any section,terms or provisions of this Agreement or the application thereof <br /> shall be held to be invalid or unenforceable,the remainder of each section, subsection,term or <br /> provision of this Agreement or the application of the Agreement to the parties, shall not be affected <br /> thereby. <br /> P. SCHEDULE. The City and Consulting Engineer are aware that many factors outside the Consulting <br /> Engineer's control may affect the Consulting Engineer's ability to complete the services to be <br /> provided under this Agreement. The Consulting Engineer will perform these services with reasonable <br /> diligence and expediency consistent with sound professional practices. The Consulting Engineer <br /> shall prepare and submit for City approval a schedule for the performance of the Consulting <br /> Engineer's services. This schedule shall include reasonable allowances for review and approval times <br /> required by the City, perfonnance of services by the City's consultants, and review and approval <br /> times required by public authorities having jurisdiction over the Project. This schedule shall be <br /> equitably adjusted as the Project progresses, allowing for changes in scope, character or size of the <br /> Project requested by the City, or for delays or other causes beyond the Consulting Engineer's <br /> reasonable controL If the Consulting Engineer becomes aware of delays due to time allowances for <br /> review and approval being exceeded, delay by the Contractor,the City,the City's consultants or any <br /> other cause beyond the control of the Consulting Engineer, which will result in the schedule for <br /> performance of the Consulting Engineer's services not being met,the Consulting Engineer shall <br /> promptly notify the City. If the City becomes aware of any delays or other causes that will affect the <br /> Consulting Engineer's schedule,the City shall promptly notify the Consulting Engineer. In either <br /> event,the Consulting Engineer's schedule for performance of its services shall be equitably adjusted. <br /> 13 <br />