|
of the Work for conformance with the Contract Documents upon Substantial Completion,(2)results of subsequent
<br /> tests and inspections,(3)correction of minor deviations from the Contract Documents prior to completion,and(4)
<br /> specific qualifications expressed by the Engineer.
<br /> § 3.6.3.2 The issuance of a Certificate for Payment shall not be a representation that the Engineer has(1)made
<br /> exhaustive or continuous on-site inspections to check the quality or quantity of the Work,(2)reviewedconstruction
<br /> means,methods,techniques,sequences or procedures,(3)reviewed copies of requisitions received from
<br /> Subcontractors and suppliers and other data requested by the Owner to substantiate the Contractor's right to payment,
<br /> or(4)ascertained how or for what purpose the Contractor has used money previously paid on account of the Contract
<br /> Sum.
<br /> § 3.6.3.3 The Engineer shall maintain a record ofthe Applications and Certificates for Payment.
<br /> § 3.6.4 Submigals
<br /> § 3.6.4.1 The Engineer shall review the Contractor's submittal schedule and shall not unreasonably delay or withhold
<br /> approval of the schedule.The Engineer's action in reviewing submittals shall be taken in accordance with the
<br /> approved submittal schedule or,in the absence of an approved submittal schedule,with reasonable promptness while
<br /> allowing sufficient time,in the Engineer's professional judgment,to permit adequate review.
<br /> § 3.6.4.2 The Engineer shall review and approve,or take other appropriate action upon,the Contractor's submittals
<br /> such as Shop Drawings,Product Data and Samples,but only for the limited purpose of(1)checking for compliance
<br /> with applicable laws,statutes,ordinances,orders,codes,rules and regulations,and(2)checking that the Work
<br /> affected by and represented by such submittals is in general conformance with requirements of the Contract
<br /> Documents.Review of such submittals is not for the purpose of determining the accuracy and completeness of other
<br /> information such as dimensions,quantities,and installation or performance of equipment or systems,which are the
<br /> Contractor's responsibility!The Engineer's review shall not constitute approval of safety precautions or construction
<br /> means,methods=techniques,sequences or procedures.The Engineer's approval of a specific item shall not indicate
<br /> approval of an assembly ofwhich the item is a component.
<br /> § 3.6.4.3 If the Contract Documents specifically require the Contractor to provide professional design services or
<br /> certifications by a design professional related to systems,materials,or equipment,the Engineer shall specify the
<br /> appropriate performance and design criteria that such services must satisfy.The Engineer shall review and take
<br /> appropriate action on Shop Drawings and other submittals related to the Work designed or certified by the
<br /> Contractor's design professional,provided the submittals bear such professional's seal and signature when submitted
<br /> to the Engineer.The Engineer's review shall be for the limited purpose of checking for conformance with information
<br /> given and the design concept expressed in the Contract Documents.The Engineer shall be entitled to rely upon,and
<br /> shall not be responsible for,the adequacy and accuracy of the services,certifications,and approvals performed or
<br /> provided by such design professionals.
<br /> § 3.6.4.4 Subject to Section 4.2,the Engineer shall review and respond to requests for information about the Contract
<br /> Documents.The Engineer shall set forth,in the Contract Documents,the requirements for requests for information.
<br /> Requests for information shall include,at a minimum,a detailed written statement that indicates the specific Drawings
<br /> or Specifications in need of clarification and the nature of the clarification requested.The Engineer's response to such
<br /> requests shall be made in writing within any time limits agreed upon,or otherwise with reasonable promptness.If
<br /> appropriate,the Engineer shall prepare and issue supplemental Drawings and Specifications in response to the
<br /> requests for information.
<br /> § 3.6.4.5 The Engineer shall maintain a record of submittals and copies of submittals supplied by the Contractor in
<br /> accordance with the requirements of the Contract Documents.
<br /> § 3.6.5 Changes in the Work
<br /> § 3.6.5.1 The Engineer may order minor changes in the Work that are consistent with the intent of the Contract
<br /> Documents and do not involve an adjustment in the Contract Sum or an extension of the Contract Time.Subject to
<br /> Section 4.2,the Engineer shall prepare Change Orders and Construction Change Directives for the Owner's approval
<br /> and execution in accordance with the Contract Documents.
<br /> § 3.6.5.2 The Engineer shall maintain records relative to changes in the Work.
<br /> In it AIA Document 8101"-2017.Copyright a 1974,1978,1987,1997,2007 and 2017 by The American Institute of Architects.AN rights reserved.The'Am n
<br /> Institute of Architects,"'°ABA,"the AIA ,and`AIA Conti Documenty are registered arks and may not be used without fission.This document was
<br /> / produced by AIA software at 18;49.33 ET on 10/28/2021 under Order No.0378037672 which expires on 08/23/2022,is not resale,is licensed for one-time use 12
<br /> only,and may only be used in accordance with the AIA Contract Documents Terms of Service.To report copyright violations,e-mail ca n h# ala_
<br /> User Notes: � 9 �y �^
<br /> (1733055828)
<br />
|