Laserfiche WebLink
' ' Mr. Stephen P. Swanson <br /> City of Decatur <br /> Page 5 <br /> July 27, 1999 <br /> Payment <br /> ENGINEER will submit on a monthly basis standard invoices for the PROJECT, and the <br /> OWNER will pay the ENGINEER within 30 days of receipt and verification by the OWNER of <br />' each invoice. At ENGINEER's discretion, OWNER shall reimburse ENGINEER at a rate not <br /> to exceed 1 percent per month applied against payments not made within 30 days of invoice <br /> Submittal to OWNER. <br /> Chan�es <br /> 1. The OWNER may,at any time,make changes within the general scope of this Agreement <br /> in the services to be performed. If such changes cause an increase or decrease in the <br /> ENGINEER's cost of or time required for performance of any services under this <br /> Agreement,an equitable adjustment shall be made,and the agreement shall be modified <br /> in writing accordingly. <br /> 2. No services for which an additional com ensation will be charged by the ENGINEER <br /> P <br /> shall be furnished without the written authorization of the OWNER. The total estimated <br /> fees shall not be exceeded without agreement by the OWNER,but may be adjusted for <br /> time delays, time extensions, amendments, or changes in the scope of services. <br /> Schedule <br /> The schedule assumes that a notice to proceed and transfer of existing information will occur on <br /> August 9, 1999. A draft report will be prepared and presented to the City in 14 weeks followed <br /> by a final meeting within 2 additional weeks. A final report is expected in early December 1999. <br /> Termination <br /> This Agreement may be terminated in whole or in part in writing by either party subj ect to a two- <br /> week notice and the right of the party being terminated to meet and discuss the termination <br /> before the termination takes place. The ENGINEER shall be paid for all completed services up <br /> to the date of termination. <br /> Remedies <br /> Except as may be otherwise provided in the Agreement,all claims,counterclaims,disputes,and <br /> other matters in question between the OWNER and the ENGINEER, arising out of or relating <br /> to this Agreement or the breach thereof,will be decided first by mediation if the parities hereto <br /> mutually agree or with a court of competent jurisdiction within the State of Illinois. <br /> STF3AND <br /> ASSOC14TE5.INC <br />