|
practicing in the same or similar IocaGty under the same or similer cic�umstances("standerd of care").
<br /> Notwithstanding aaything to ttie contiary,all Services shall be subject to,and judged solely against,the sKaadacd of
<br /> care set forth in t6e previous senteuce,snd the Architect makes no wazranties,express or implied,regarding the
<br /> provisian of professionat services,the instruments of service,or the outcome of the Project The Arclatect shsl!
<br /> perform its services as expedidausly as is consistent with such ptofessional skill and care and t4e orderly progress af
<br /> thc Ptojeck In the event Arcttitect is hindered,delayed or prcvented from perfornung its obligations uader this
<br /> Agreement as a result of eny fire,flood,landslide,tomado or ot6er act af God,maticious mischief,theft,strike,
<br /> lockout,other labor problems,shorteges of materiaF or labor.failure of any governmental egeacy or Qwner to fiunish
<br /> infornoation or to approve ot ta disapprove Ar�hitect's wark or any oWer cause beyond the reasonable control of
<br /> Architect,the time and compensadoa for completion of ArchitecYs work shail be equitably edjusted to account for the
<br /> inccease ia the cost and emaunt uf tiare required ta gerform the services msulting from such delay.
<br /> §2.3 T6e Arciutect shalt ideadfy a represeatstive aukhoriud to act on behatf of the Architect widi respect to the
<br /> Project
<br /> §2.4 Except with the Owner's knowledge and consent,the Architect shall not engage in any activity,or accept any
<br /> employment,interest or coattibution that would reasonably appcer to campmmise the Architect's profcssioaal
<br /> judgment wiW respect to this Project.
<br /> §2.5 The Arctutect shall meintaia the follawing insurance until teraiina;tion of this Agreement.If any of the
<br /> requirements set forth bclow arc ia addition to the types end limits the Architect normal[y maintains,the Owner shall
<br /> pay the Architect as set forth ia Section 1 I.9.
<br /> §2.5.9 Commercial General LiabiEity with poticy limits ofnot less than One Millson and Not104 Dollars(S 1,000,000
<br /> }for each occurrence and Two MiUian and No/100 Dollars(�2,000,000)in the aggregate for badily injury and
<br /> progerty damage.
<br /> §2.5.2 Automobile Liability covering vehicles owned,aad non-owned vehicles used,by the Architect with policy
<br /> limits of not less t6an Two Millioa end No/100 Dollars($2,OOU,000)pet sccident for bodi{y injury,deaW of any
<br /> person,and property damagc arising out of the owaership,mainteaancc and use of Wose motor vel�icles,along with
<br /> any oWer statuWrily required automobile covera�;e.
<br /> §2.5.3 The Architect may achieve t6e requiced limits and coverage for Commerciai Geaeral Liability and Automobile
<br /> Liability through e combinatian of primary and excess or umhrella liability insurance,provided such primary snd
<br /> excess or umbrella liability insurance polieies result ia the same or greater coverage ss the coverages requixed under
<br /> Sections 2.5.1 and 2.5.2,ead ia ao event shalf any excess or urnbrella liability insutance provide narrower caverage
<br /> than the primary policy.The eaccess policy sdalt not require the exhaustion of the underlying limits oaly through the
<br /> actual paymcnt by thc uadcrlying insurcrs.
<br /> §2.5.4 Workcrs'Compcasadan at statutory limits.
<br /> §2.5.5 Employcrs'Liability witI�poticy limits not less than One Millioa and No1100 Dollars ($ 1,Q00,000)each
<br /> accidcnt, One Million and No/104 Dollars (�I,Qd0,00(f)cach cmployec,and Onc Million and Noi100 Doliars ($
<br /> 1,000,0�)poticy limix
<br /> §2.5.6 Profcssional Liability covering negligent acts,errors and omissions in the performance af professional sen+ices
<br /> with palicy Iimiis of not less tl�an Two Million and No/i0D Dolla�s (S 2,000,000)per claim a�d Two Million and
<br /> No/100 Dollars ($Z,000,000)in thc aggrcgetc,
<br /> §2.5.7 Additional(nsured Obligattons.To thc Cullcst cxtent pcmiiucd by law,the Archiuxt shalt causc thc primary and
<br /> e�ccess or umbrella policcs for Commcreial Gcncral Liability and Automabilc Liability to includc thc Owncr as an
<br /> additional insuned for claims caused in whole or in part by the Architect's negligent acts or amissions.The additional
<br /> insured coverage shall be primary and non-contnbutory to any of the Owner's insurance policies and s6a11 apply to
<br /> both ongoing and complcted operations.
<br /> IUA DoewnMt 8101"'-2D17.Copydpht O 1974,1978,1@8T,1997,�07and 2077 hyThe Amarkan MsUWiaof Arct�tects.All tiphtt nsmred.WARNIHG:Thls
<br /> Inik p�qs pocumont ts protoctod by U.S.Copyright Lawand IntemaUonal Treades Unautharizod roproduttlon ordfstributlon otthts AW'Documont,ornny s
<br /> portian of It,may nesuit Fn sovero civfl and crtminal psnaltles,und wip!ao prosowbed to the ma�slmum extsnt possibte undar the law.Thb dopxnetrt was
<br /> / pr�uced by AlA wNvrare at 1439•55 ET on 11I22f2Dt9 undar Ordar No.9334820349 whkh expkss on U9l10I2Q20,ar�f is twl for resale.
<br /> Ussr Notes: (1230398033)
<br />
|