Laserfiche WebLink
GENERAL CONDITIONS <br /> GC-10 FAIR EMPLOYMENT PRACTICES <br /> The Contractor and all subcontractors hereunder must comply with the provisions of the <br /> Illinois Human Rights Commission's Rules and Regulations for public contracts and the Equal <br /> Employment Opportunity Clause as contained in the Special Conditions of the Contract. <br /> GC-11 INDEMNIFICATION <br /> The Contractor agrees to indemnify and hold harmless the City of Decatur, and its <br /> officers and its employees, from and against all liability, claims, demands and expenses, <br /> including court costs and attorney fees, on account of any injury, loss or damage which arise out <br /> of or are in any manner connected with the work to be performed under this Agreement, if such <br /> injury, loss or damage is caused in whole or in part by, or is claimed to be caused in whole or in <br /> part by the negligent acts, errors or omissions of the Contractor, any Subcontractor of the <br /> Contractor, or any officer employee or agent of the Contractor. The obligations of this Section <br /> shall not apply to damages which the City of Decatur shall become liable by final judgment to <br /> pay to a third party as the result of the negligent act, error or omission of the City of Decatur, its <br /> officers, employees or agent of the City of Decatur. <br /> GC-12INSPECTION <br /> The Contractor shall give sufficient advance notice of lacing orders to permit tests to be <br /> g p <br /> completed before the materials are incorporated in the work and he shall afford such facilities as <br /> the Engineer may require for collecting and forwarding samples and making inspections. All <br /> costs connected with the furnishing and testing of samples will be borne by the Contractor. <br /> Independent testing laboratories may be used provided they meet the approval of the City. <br /> GC-13 LANE CLOSURE PERMITS <br /> Not Applicable <br /> GC-14 LIQUIDATED DAMAGES <br /> Article 108.09, Failure to Complete the Work on Time, of the Illinois Department of <br /> Transportation (IDOT) "Standards and Specifications for Road and Bridge Construction", <br /> adopted January 1, 2012, shall be used for this project. <br /> GC-15 LOCATION OF UTILITIES <br /> Prior to commencing construction, the Contractor shall contact JULIE (1-800-892-0123), <br /> and those agencies listed below to secure utility locations and data: <br /> City of Decatur (JULIE Member) <br /> AmerenIP (JULIE Member) <br /> AT&T (JULIE Member) <br /> Comcast Cable (JULIE Member) <br /> 25 i <br />